Terms & Conditions

1. AGREEMENT

  1. 1.1.  The agreement is between Giorgos and the Client, whereby the Client engages Giorgos in relation to the New Home Agency (“the New Home Agency”), whereby:

    1. (a)  Giorgos will offer a no cost service to the Client of providing consulting services to match the Client with a Builder to suit the particular building project that the Client wishes to carry out in accordance with the requests of the Client; and

    2. (b)  Giorgos will promote house and land packages but will then match the Client with a Builder to suit the particular house and land building project that the Client wishes to carry out in accordance with the requests of the Client.

  2. 1.2.  The Agreement will consist of the following documents:

    1. (a)  These Terms and Conditions;

    2. (b)  The Terms and Conditions contained within the Website; and

    3. (c)  The Disclaimer on the Website.

2. TERM

2.1. Subject to termination in accordance with clause 11 the approximate term for the completion of the New Home Agency is as follows:

(a) Unless either party notifies the other party in writing prior to the end of the term, this agreement continues until the New Home Agency are completed.

3. CHARGES, PAYMENT BILLING & BILLING DISPUTES

Invoiced Charges

  1. 3.1.  There will be no cost payable to Giorgos for the provision of the New Home Agency, however the Client understands that the Building Contractor will provide a quote to Giorgos that Giorgos will then forward direct to the Client on the Building Contractor’s behalf, and Giorgos will sign documents on the Building Contractor’s behalf. The Building Contractor will issue invoices direct to the Client pursuant to the Building Services the Building Contractor provides to the Client and the Client will be bound by such terms and conditions of the invoices issued by the Building Contractor.

  2. 3.2.  The Client understands that Giorgos will not issue any invoices to the Client direct for the New Home Agency as Giorgos does not charge any fees or charges to the Client for the New Home Agency that Giorgos provides to the Client.

Commission

  1. 3.3.  The Client acknowledges that Giorgos will be paid a commission from the Building Contractor as a fee for service.

  2. 3.4.  The Client acknowledges that Giorgos is receiving the same commission as outlined in clause 3.3 from each building contractor.

4. PROVISIONS APPLICABLE TO THE NEW HOME AGENCY

Provision of Service

4.1 Subject to the Client‘s compliance with the agreement, Giorgos will use its best endeavours to provide the New Home Agency in accordance with the agreement and the requests of the Client made during consultations with Giorgos.

4.2 Giorgos will advise the Building Contractor of the requests made by the Client during consultations with Giorgos, and any arrangements made for Building Services associated with the build of the home will be between the Client and the Building Contractor.

4.3 All contracts in relation to the Building Services are between the Client and the Building Contractor direct and once such contract has been signed, the Client must liaise with the Building Contractor direct and any after sale service will be between the Client and the Building Contractor direct unless otherwise agreed in writing between the Client and Giorgos.

4.4 Giorgos shall not be liable for any Liability incurred by the Client due to a failure of the Building Contractor to commence any building services that they have been engaged to complete on the Commencement Date or complete the Building Services within the Estimated Time Frame.

Co-operation with Giorgos

4.5.

The Client must cooperate with Giorgos and comply with any of its reasonable requests to allow Giorgos to supply the New Home Agency to the Client efficiently. This includes meeting Giorgos’ reasonable requests, at no further cost to Giorgos, to:

(a) provide any necessary forecasts and information to Giorgos, on which Giorgos will rely in establishing and supplying the New Home Agency to the Client.

Client’s Obligations:
4.6. The Client must not use, or attempt to use, the New Home

Agency:

  1. (a)  To breach any term of the agreement;

  2. (b)  For any improper or unlawful purpose or allow others to do so;

  3. (c)  In breach of any applicable Government Agency requirements, legislation and laws including but not limited to any privacy laws; copyright laws and telecommunications laws;

  4. (d)  To expose Giorgos to any Liability;

  5. (e)  In any way which damages, interferes with or Interrupts the New Home Agency that Giorgos provides to the Client or the Building Services the Building Contractor provides to the Client;

  6. (f)  In any way which may damage any property or injure or kill any person; or

  7. (g)  To transmit, publish or communicate material which is defamatory, offensive, abusive, indecent, menacing or unwanted.

4.7 The Client must:

(a) Liaise direct with the Building Contractor after a contract between the Client and Building Contractor in relation to the Building Services has been fully signed.

5. DISPUTES PROCEDURE

5.1. The parties shall co-operate to investigate promptly and resolve any dispute concerning any issue arising pursuant to the agreement.

Compulsory

5.2 If a dispute arises out of or relates to the Terms, either party may not commence any Tribunal or Court proceedings in relation to the dispute, unless the following clauses have been complied with (except where urgent interlocutory relief is sought).

Notice

5.3 A party to the Terms claiming a dispute ('Dispute') has arisen under the Terms, must give written notice to the other party detailing the nature of the dispute, the desired outcome and the action required to settle the Dispute.

Resolution

  1. 5.4  On receipt of that notice ('Notice') by that other party, the parties to the Terms ('Parties') must:

    1. Within 14 days of the Notice endeavour in good faith to

      resolve the Dispute expeditiously by negotiation or such

      other means upon which they may mutually agree;

    2. If for any reason whatsoever, 14 days after the date of the Notice, the Dispute has not been resolved, the Parties must either agree upon selection of a mediator or request

      that an appropriate mediator be appointed.

    3. The Parties are equally liable for the fees and reasonable expenses of a mediator and the cost of the venue of the mediation and without limiting the foregoing undertake to pay any amounts requested by the mediator as a pre- condition to the mediation commencing. The Parties must

      each pay their own costs associated with the mediation;

    4. If the dispute remains unresolved, either party may, on giving written notice to the other party to such effect, commence legal proceedings in an appropriate court to

      resolve the matter.

  2. 5.5  During the existence of any dispute, the parties must continue to perform all of their obligations under the agreement, without prejudice to their position in respect of the dispute unless the parties agree otherwise.

  3. 5.6  Nothing in this clause prevents a party from seeking urgent interlocutory relief required in relation to the agreement.

6. COMPLIANCE WITH GOVERNMENT AGENCY REQUIREMENTS

  1. 6.1  In the event that Giorgos is unable to provide the New Home Agency substantially in the form and of the type contemplated under the agreement due to any direction of a Government Agency, law, rule, regulation, statute or ordinance then Giorgos shall provide notice to the Client of that fact as expeditiously as possible and shall not be liable for any Liability incurred by the Client as a result of Giorgos’ failure to provide the New Home Agency as contemplated pursuant to this clause 6.

  2. 6.2  Upon receipt by the Client of a notice under clause 6.1, the Client shall be at liberty to terminate the New Home Agency without penalty by notice to Giorgos within 14 days of receipt of the clause 14.1 Notice. If the Client provides this notice to Giorgos within the said 14 days the New Home Agency shall be deemed to be terminated by the Client.

7. NATURE OF THE CONDUCT

7.1 The agreement contains the entire agreement between Giorgos and the Client and supersedes all prior communications and negotiations between the parties.

7.2 Unless otherwise specified in the agreement, no amendments or variation of the agreement is valid or binding on a party unless made in writing and signed by the Client and Giorgos.

8 INDEMNITY

8.1 The Client shall indemnify Giorgos from and against any Liability which may be incurred or suffered by Giorgos arising from any one or more of the following:

(a) the breach by the Client of a material term or any of the Client’s obligations under the agreement;

(b) any negligent act or omission or wilful misconduct by the Client arising from the use of the New Home Agency, or otherwise arising out of the Client‘s obligations under theagreement;

(c) Any direct or indirect consequence of the Client accessing, using or transacting on the Website or attempts to do so;

(d) Any beach of the terms;

(e) the use or provisioning of the New Home Agency; and

(f) any claims or demands made upon Giorgos by reason of any loss, injury or damage which may be suffered by any person from the provisioning or use of the New Home Agency.

9 DISCLAIMER

9.1 The Client understands and acknowledges that Giorgos will provide the New Home Agency but will engage Building Contractors to undergo the Building Services.

9.2 The Client understands and acknowledges that the Building Contractors referred are independent of Giorgos.

9.3 The Client understands and acknowledges that Giorgos is not the builder.

9.4 The Client understands and acknowledges that Giorgos’ process involves a schematic design only.

9.5 Giorgos has not made any representation to the Client as to the work to be performed or the nature or quality of the work anticipated to be accomplished.

9.6 The Client agrees to satisfy themselves that the Building Contractors meet the standards of work that the Client requires.

9.7 The Client hereby holds Giorgos harmless from any defect in workmanship, default, damage, injury, or expense arising out of the Building Services performed by the Building Contractors.

9.8 Giorgos shall not be liable for any Liability incurred by the Client due to a failure of the Building Contractor to commence any building services that they have been engaged to complete on the Commencement Date or complete the Building Services within the Estimated Time Frame.

9.9 The Client understands and acknowledges that Giorgos is not the builder and all Building Services are carried out by independent Contractors.

9.10 The Client understands and acknowledges that Giorgos has explained all of the potential risks associated with the Building Services and/or entering into a building contract in detail and the Client is aware of such potential risks.

9.11  Giorgos does not take any responsibility and will not be held liable if the Building Contractor becomes insolvent.

9.12  Giorgos does not take any responsibility and will not be held liable for any changes in pricing pursuant to invoices between
the Client and the Building Contractor.

9.13  The Client understands and acknowledges that all contracts in relation to the Building Services are between the Client and the Building Contractor direct. Giorgos makes no representations in regard to the suitability of any of the terms of such contract
for Building Services.

9.14 The Client acknowledges that the land on which the Building Services are conducted is not owned by Giorgos, including but not limited to any of the land referred to by Giorgos in relation to the house and land packages.

9.15 In the event the Client decides to proceed with a different builder to carry out the Building Services other than the one that Giorgos has recommended to the client, then in such case Giorgos makes no representations in regard to the suitability of the builder to carry out the Building Services and does not provide any guarantees or representations in relation to the success of the Building Services to be carried out.

9.16  The Client understands and acknowledges that all designs and materials produced by Giorgos are covered by copyright pursuant to clause 12.

9.17  The Client understands and acknowledges that the Building Services to be carried out by the Building Contractor are subject to council approval and any and all other relevant required approvals which are to be carried out by the Building Contractor direct.

9.18  Giorgos does not take any responsibility and will not be held liable if the Client requires any retaining, special approvals or special requirements.

9.19  The Client understands that prices may vary depending on selections, engineering, council requirements and adjustments to allowances.

9.20  The Client understands that in the event that retaining walls arerequired on the land by which the Building Services are to be carried out, then it is the Client’s responsibility to arrange the retaining walls and any required approvals and/or consents with the adjoining neighbour(s) and neither Giorgos nor the Building Contractor will take any responsibility for the retaining walls and Giorgos has not made any allowance for any retaining walls in any quote provided to the Client.

9.21  The Client understands and acknowledges that Giorgos makes no representations in regard to the suitability of the land to build on or otherwise.

9.22  The Client understands and acknowledges that Giorgos carries out the New Home Agency around the block dimensions only with overall parameters set. The Client agrees that they must carry out their own inspections and/or obtain independent professional advice or otherwise in order to satisfy themselves of the block dimensions.

9.23  The Client understands and acknowledges that in order for the Building Services to proceed, all Plans are subject to any remaining relevant processes.

9.24 The Client understands and acknowledges that all Plans are subject to engineering requirements.

9.25 The building company that is involved with this house and land package is independent of Giorgos.

9.26 Giorgos makes no representations in regard to the suitability of the land to build on for house and land packages or otherwise and the Client must satisfy them self of this by carrying out all relevant inspections and approvals, and the client must seek any professional advice that may be applicable.

9.27 The provisions of this clause 9 survive the termination of the New Home Agency

9.28 In the event that promotions are created by any building company direct, as indicated by Giorgos, Giorgos does not make any representation in relation to the suitability of such promotion. GIORGOS should be contacted to confirm full details of any promotions, and such promotions are subject to change at any time.

10 LIABILTY AND WARRANTIES

10.1 The Client acknowledges it has not relied on any representation or warranty made by Giorgos which has not been stated expressly in the Contract.

Giorgos will match Clients to Building Contractors based on the professional judgement of Giorgos only, and matches will not be based on financial benefit to Giorgos as Giorgos will receive the same commissions from each Building Contractor.

10.3  Except as required by law or regulations or set out in this Contract, Giorgos expressly excludes all Liability for all warranties, conditions, non-fraudulent representations express or implied concerning the New Home Agency, including but not limited to those relating to the availability, performance quality or fitness for purpose of the Service.

10.4  To the extent permitted by law Giorgos will not be liable for any special, indirect or consequential loss or damage (unless such loss or damage is reasonably foreseeable resulting from our failure to meet an applicable Consumer Guarantee), loss of profit or opportunity, or damage to goodwill arising out of or in connection with the New Home Agency or these Terms (including as a result of not being able to use the New Home Agency or the late supply of the New Home Agency), whether at common law, under contract, tort (including negligence), in equity, pursuant to statute or otherwise.

10.5 Under no circumstances will Giorgos be liable to the Client for loss of profit, loss of contracts or for any indirect economic or consequential loss whatsoever, whether arising from negligence, breach of contract or otherwise. This shall include but is not limited to loss caused by the following:

10.5.1  The Client breaching any provision of the Terms or intending to breach any provision;

10.5.2  Giorgos is required to terminate the contract by law or;

10.5.3  The provision of the New Home Agency to the Client by Giorgos is, in the opinion of Giorgos, no longer commercially viable.

10.6 Use of the Website and the New Home Agency is at the Client’s own risk. Everything on the Website and the New Home Agency is provided to the Client "as is" and "as available" without warranty or condition of any kind. None of the affiliates, directors, officers, employees, agents, contributors and licensors of Giorgos make any express or implied representation or warranty about the New Home Agency or any products or Services (including the products or the New Home Agency of Giorgos) referred to on the Website. This includes (but is not restricted to) loss or damage the Client might suffer as a result of any of the following:
1. Failure of performance, error, omission, interruption,

deletion, defect, failure to correct defects, delay in operation or transmission, computer virus or other harmful component, loss of data, communication line failure, unlawful third party conduct, or theft, destruction, alteration or unauthorised access to records;

2. The accuracy, suitability or currency of any information on the Website, the New Home Agency or any of the New Home Agency’s related products (including third party material and advertisements on the Website);

3. Costs incurred as a result of the Client using the Website, the the New Home Agency or any of the products of Giorgos; and

4. The the New Home Agency or operation in respect to links which are provided for the Client’s convenience.

10.7 The provisions of this clause 10 survive the termination of the Service.

11 TERMINATION AND SUSPENSION

Termination by Giorgos

  1. 11.1  Giorgos may, without liability, terminate the Contract or provisioning of the New Home Agency at any time after the Commencement Date, if Giorgos reasonably determines that it is not technically or operatively feasible or commercially viable to supply the New Home Agency to the Client.

  2. 11.2  Subject to local applicable laws, Giorgos reserves the right to terminate this contract at any time and may suspend or deny, in its sole discretion, the client’s access to all or any portion of the Website or the New Home Agency without notice if the Client breaches any provision of the terms of the Contract or any applicable law or if the Client’s conduct impacts Giorgos' name or reputation or violates the rights of those of another party.

  3. 11.3  Giorgos may, without liability, at its option either terminate or suspend the Contract by giving notice to the Client if:

    1. (a)  The Client suffers an Insolvency Event; or

    2. (b)  Giorgos is required to do so under any law or to comply with an order, instruction or request of a Government Agency, an emergency services organisation or any other competent authority.

Termination by Client

11.4 The Client may after the Commencement Date, terminate the Contract if:

  1. (a)  it does pursuant clause 6.2; and

  2. (b)  Giorgos commits a serious breach of the Contract, and has not remedied that breach within 30 days of becoming aware of that breach.

Termination By Either Party

11.5 Either party (“Affected Party”) may, without liability, terminate the Contract with immediate effect from the date of service of a notice (or with effect from a later date as the Affected Party may nominate in a notice) if any Force Majuere Event prevents the supply of the New Home Agency for more than 30 consecutive day.

Following Termination

11.6 On termination of the Contract for any reason:

(a) each party must, on request by the other party, immediately return or destroy the other party’s Confidential Information, except to the extent that it is required by law to retain the other party’s Confidential Information;

(b)  Giorgos may immediately stop supplying to the Client the New Home Agency;

(c)  unless the Contract expressly states otherwise, each persons’ accrued rights and obligations are not affected; and

(d)  the clauses of the Contract which are by their nature intended to survive cancellation of the New Home Agency will do so, which for the purposes of these General Conditions, include clauses 8, 9, 10, 13, and 16.

12 INTELLECTUAL PROPERTY

12.1 For all plans that are provided by the Building Contractor, the parties understand and acknowledge that the copyright to the building plans and designs are owned by the Building Contractor.

12.2 For all plans that are provided by Giorgos, the parties understand and acknowledge that Giorgos owns all of the copyright in all designs and materials produced by Giorgos.

12.3 Giorgos owns the copyright in all designs and materials created by Giorgos and the Client must not take any plans created by Giorgos to any builder to carry out the Building Services other than the one that Giorgos has recommended to the client or the Building Contractor that Giorgos has recommended unless Giorgos does so on behalf of the Client.

12.4 Giorgos owns all material (including the Intellectual Property Rights) developed by it, or its personnel, or at its or their discretion.

12.5 Giorgos may permit the Client to use this material, or other material licensed by Giorgos, as part of the New Home Agency. This permission is subject to any conditions which Giorgos may impose from time to time and will cease when the New Home Agency is cancelled.

13 CONFIDENTIALITY

13.1 Giorgos and the Client each agree to keep confidential the other’s Confidential Information and to not use the Confidential Information for any purpose other than that for which it was disclosed or which may cause the Provider loss.

13.2 The Provider retains all property rights in the Confidential Information.

13.3 The Recipient may disclose Confidential Information (to the extent reasonably necessary) to its Representatives for the sole purpose of assisting the Recipient for purposes related to the supply of the New Home Agency (or for the purposes which would be reasonably expected) including billing and account management, business planning and product development.

13.4 The obligations of confidentiality in this clause 13 do not apply to the extent disclosure is required by law or the rules of a stock exchange, a direction by Government Agency, or disclosure to professional advisors in connection with the supply of the New Home Agency .

13.5 The Recipient acknowledges that a breach of this clause 13 may cause the Provider irreparable damage for which monetary damages would not be an adequate remedy. Accordingly, in addition to other remedies that may be available, the Provider may seek injunctive relief against such a breach or threatened or suspended breach.

13.6 The Recipient‘s obligation with respect to the Confidential Information survive termination and bind the Recipient until the

relevant Confidential Information has become part of the public domain other than in breach of an obligation of confidentiality.

14 NOTICES

14.1 Notices for the purpose of the Contract shall be in writing. A notice given to a party at that party’s address set out on the face or at such other address as may be substituted by written notice from such party to the other shall:

  1. (a)  in the case of prepaid post, be presumed to be given 5 days after the date of posting;

  2. (b)  be presumed to be delivered at the time of delivery if delivered during normal business hours;

  3. (c)  be presumed to be given upon receipt by the sender of a satisfactory transmission confirmation report indicating due transmission without error

  4. (d)  in the case of facsimile transmission.

  5. (e)  be presumed to be given upon the sender’s computer system indicating transmission in the case of an email transmission.

15 WAIVERS

15.1 No waiver or indigence by any party to the Contract shall be binding upon the parties unless in writing.

16 GOVERNING LAW

16.1 This Contract shall be governed by law of South Australia and the parties agree to submit to the jurisdiction of the Courts of South Australia.

17 COUNTERPARTS

17.1 This Contract may be executed in any number of counterparts and by the parties on separate counterparts. Each counterpart constitutes the agreement of each part who has executed and delivered that counterpart.

18. CONFLICT OF INTEREST

18.1  In order to avoid any conflict of interest, the Client acknowledges that in the event the Client has already engaged a particular builder or Contractor to carry out Building Services, Giorgos will be unable to match, refer, transfer or recommend the Client to a different builder or Contractor, other than in the event that the Client is engaged independently through the Company as outlined in clause 18.3.

18.2  In the event that the client returns to use the services of the Giorgos, then the Giorgos will be able to continue working with the Client and will be able to match the Client to engage the services of any other builder and /or contractor after a period of twelve (12) months from the date of the original Building Contract.

18.3  In the event that the Client has been engaged independently through the Company, then in such case the Company will match the Client to any builder the Company recommends based on the Clients requests and the nature of the Client’s project.

18.4  In the event that the Giorgos has used marketing material of a particular building company, including but not limited to social media, plans and any other relevant promotional material, to attract clients, then the Clients will be required to be matched with that particular builder company.

18.5  In the event that the Client does not agree to be matched with the corresponding building company pursuant to clause 18.4 then Giorgos reserves their right to terminate this agreement in accordance with clause 11 but immediately.

19. DEFINITIONS

Building Contract means the building contract entered into between the Building Contractor and the Client direct for the Services that the Contractor is to carry out.

Building Services means the building works to be conducted by the Building Contractor in accordance with the client’s requests and pursuant to a building contract to be signed between the Building Contractor and the client direct.

Business Day - means a business day in the city where the Service is provided.

Client – means the Client engaging Giorgos to carry out the New Home Agency and any of its employees, sub-contractors, agents and representatives.

Commencement Date - means, unless otherwise agreed, the day that the Building Contractors are to commence the Building Services.

Confidential Information - of a party means all information of a confidential nature relating to that party including anything which is indicated to be subject to an obligation of confidence which is disclosed by that party to the other party in relation to this Contract to supply service or comes to the knowledge or into the possession of the other party in connection with this Contract but does not include information:

(a)  the party creates (whether jointly or alone) independently of the other party’s Confidential Information;

(b)  that is public knowledge (other than as a result of a breach of confidentiality by the party or any person to whom the party has disclosed the information); or

(c)  obtained without restriction as to the further disclosure from a source other than the other party through no breach of confidentiality by that source.

Building Contractor means the independent builders, as chosen by Giorgos, and any of its employees, sub-contractors, agents and representatives to be connected to clients to suit the particular building project being carried out by the Client, in accordance with the requests of the Client.

Day or day - means any day not limited to a Business Day.
Due Date - 21 days from the date the Invoice, unless specified

otherwise by Giorgos.

Estimated Time Frame means unless otherwise agreed, the time frame by which the Building Contractor is to complete the Building Services within.

Excluded Event – means:

(a)  a breach of the Contract by the Client;

(b)  a Force Majeure Event;

(c)  a negligent or fraudulent act or omission of the Client’s personnel; or

(d)  a failure of any of the Client’s Equipment.

Force Majeure Event – means:

(a) any act of god or act of nature, fire, flood, storm, explosion, sabotage, riot, act of war whether declared or not, requirement or restriction of governmental authorities, inability or delay in the grant of governmental or other approvals, consent, permits, licences or authorities or any other like event; or 

(b)  any strike, lockout, work stoppage or other industrial dispute of any kind; or

(c)  any act or omission of a third party which affects the provisions of the New Home Agency, including a failure to provide goods and services; or

(d)  any other similar circumstances beyond the reasonable control of the affected party.

General Terms and Conditions – means the general term and conditions contained in this document.

Giorgos means Giorgos as operated by GSTUDIO PTY LTD ACN 605 329 306 of 79A Redward Avenue, Greenacres SA 5086.

Government Agency – means any government or governmental, semi-governmental, administrative, municipal, fiscal, or judicial body, department, commission, authority, tribunal, agency, or other statutory entity including but not limited to the Australian Communications and Media Authority, the Australian Competition and Consumer Commission, the Australian Communications Industry Forum Limited, the Telecommunications Industry Ombudsman and any other government or statutory body or authority.

Insolvency Event – means:

(a)  bankruptcy proceedings are commenced against the

Client, or the Client is declared bankrupt;

(b)  any step that is taken to enter into any scheme or arrangement between the Client and its creditors;

(c)  any step is taken by a mortgage to enter into possession or dispose of the whole or any party of the Client’s assets or business;

(d)  any step is taken to appoint a receiver, a receiver and manager, a trustee in bankruptcy, a liquidator, a provisional liquidator, an administer or other like person to the Client or to the whole or any part of the Client’s assets or business;

(e)  the Client suspends payment of its debts generally; or

(f)  the Client is or becomes unable to pay its debts when they are due or it is or is presumed to be insolvent for the purposes of any provision of the Corporation Act 2001 (Cth).

Intellectual Property Rights - means any intellectual or industrial property rights (including any registered or unregistered trademarks, patents, designs, or copyright) and includes the right to have Confidential Information kept confidential.

Interruption – In the supply of goods or a service (including the Service) means a delay in supply, a failure to supply or an error, defect in the supply of, those goods or that New Home Agency and Interrupts has a corresponding meaning.

Liability - means any direct or consequential liabilities, claims, losses, cost, charges, damages, injury or expenses of any nature.

New Home Agency means the service that the Client has engaged Giorgos to complete as outlined in clause 1.1.

Plans means the site plan and floor plan of homes.
Provider - means a party that discloses its Confidential

Information to another party.

Recipient - means a party that receives or obtains Confidential Information of another party.

Related Body Corporate has the meaning given to that expression in the Corporation Act 2001 (Cth).

Representative – means a director, officer employee or agent. Term - has the meaning given in clause 2.
Website means www.giorgos.com.au

House and land disclaimer

Any land referred to by Giorgos in relation to the house and land packages is not owned by Giorgos.  The building company that is involved with this house and land package is independent of Giorgos. Giorgos makes no representations in regard to the suitability of the land to build on for house and land packages or otherwise and you must satisfy yourself of this by carrying out all relevant inspections and approvals, and you must seek any professional advice that may be applicable. Except as required by law or regulations, Giorgos expressly excludes all Liability for all warranties, conditions, non-fraudulent representations express or implied concerning the information that is contained in this material or any representations regarding the land made by Giorgos and its related entities, including but not limited to those relating to the availability, performance quality or fitness for purpose.

 

Any pricing associated with the house and land packages may vary depending on selections made, engineering, council requirements and any adjustments to allowances. You understand that in the event that retaining walls are required on the land, then it is your responsibility to arrange the retaining walls and any required approvals and/or consents with the adjoining neighbour(s) and neither Giorgos nor the Contractor will take responsibility for the retaining walls. Giorgos has not made any allowance for any retaining walls in any quote provided to you. All images, videos and media on all of our House & Land listings are illustrative purposes only and you should contact us to confirm all details.

Promotions

In the event that promotions are created by any building company direct, as indicated by GIORGOS, GIORGOS does not make any representation in relation to the suitability of such promotion. GIORGOS should be contacted to confirm full details of any promotions, and such promotions are subject to change at any time.

Finance

The information provided herein does not constitute financial advice, has been provided for general information purposes, contains estimates only and should not be relied upon or acted upon. Always consult a professional financial adviser and/or mortgage broker for advice specific to your circumstances. Neither Giorgos nor any individual author accepts responsibility and/or liability whatsoever arising out of the use of the information herein, and/or the acts or omissions due to any reliance on the information contained herein or any links contained herein.

Floor Plans and Elevations

The floor plans and elevations are exclusive the property of Giorgos. Any reproduction without written authority is strictly prohibited. If you wish to gain authorisation please email HOME@GIORGOS.COM.AU and we can advise if costs apply. The elevations provided by Giorgos inside this website or out are strictly illustrative purposes only and you will need to speak to staff to find out more.

  • Instagram
  • LinkedIn - Grey Circle
  • Facebook
  • YouTube

JOIN GIORGOS™ VIP

Want exclusive access to our newest home designs, special offers, building ideas, promotions, latest house and land packages and more?

TOP